Introduction

Welcome to IndiaTek Solutions Private Limited ("IndiaTek", "Company", "we", "our", or "us"). These Terms & Conditions govern your use of our website and services. By accessing or using our website, you agree to be bound by these Terms & Conditions.

1. Acceptance of Terms

By accessing this website, you acknowledge that you have read, understood, and agree to comply with these Terms & Conditions, along with our Privacy Policy. If you do not agree with these terms, please do not use our website or services.

2. About IndiaTek

IndiaTek Solutions Private Limited is an Information Technology company providing digital solutions including: - Website Design & Development - Custom Software Development - Mobile Application Development - FinTech Software Development - UI/UX Design - Cloud Solutions - API Development & Integration - AI & Automation Solutions - IT Consulting - Technical Support & Maintenance

3. Use of Website

You agree to use this website only for lawful purposes. You shall not: - Attempt unauthorized access to our servers. - Upload malicious software or viruses. - Copy website content without permission. - Interfere with website security. - Use our website for fraudulent activities. - Misrepresent your identity. Violation of these terms may result in legal action.

4. Intellectual Property

Unless otherwise stated, all content available on this website including: - Logos - Graphics - Icons - Website Design - Source Code - Images - Text - Videos - Animations - Software - Documents is the exclusive property of IndiaTek Solutions Private Limited and is protected under applicable intellectual property laws. No content may be copied, reproduced, distributed, modified, or reused without prior written consent.

5. Services

All services are provided based on mutually agreed proposals, quotations, contracts, or service agreements. Project scope, pricing, timelines, and deliverables will be defined before project commencement. Any additional work outside the agreed scope may incur additional charges.

6. Client Responsibilities

Clients agree to: - Provide accurate information. - Submit required project materials on time. - Review deliverables promptly. - Approve milestones within the agreed timeline. - Make payments according to the agreed schedule. Project delays caused by the client may affect delivery timelines.

7. Pricing & Payments

Project pricing is based on the approved quotation or agreement. Payments may be required in milestones. Invoices should be paid within the specified due date. Late payments may result in: - Project suspension - Delayed delivery - Additional late payment charges where applicable All applicable taxes will be charged as per government regulations.

8. Refund Policy

Payments made for completed work are generally non-refundable. Refund requests, if applicable, will be reviewed on a case-by-case basis in accordance with the signed agreement. Third-party expenses, domain registrations, hosting fees, software licenses, and API subscription charges are non-refundable.

9. Project Delivery

Estimated delivery dates are approximate. Delivery timelines may change due to: - Client-requested revisions - Delayed approvals - Scope changes - Force majeure events - Third-party service delays We will make reasonable efforts to keep clients informed of any significant delays.

10. Third-Party Services

Projects may involve third-party products or services such as: - Cloud Hosting - Payment Gateways - Domain Registrars - Email Providers - SMS Services - APIs - Analytics Platforms IndiaTek is not responsible for interruptions, pricing changes, or policies of third-party providers.

11. Confidentiality

Both parties agree to keep confidential information private and not disclose it to third parties unless required by law or with prior written consent.

12. Limitation of Liability

To the maximum extent permitted by law, IndiaTek shall not be liable for: - Business interruption - Data loss - Loss of profits - Indirect or consequential damages - Security breaches caused by third-party services - Unauthorized access resulting from client negligence Our total liability shall not exceed the amount paid for the specific service giving rise to the claim.

13. Warranty Disclaimer

Services are provided on an "as is" and "as available" basis. While we strive to deliver reliable solutions, we do not guarantee that: - The website will always be error-free. - Services will be uninterrupted. - Third-party systems will always function properly. - Software will be completely free from bugs or vulnerabilities.

14. Cancellation

Either party may terminate a project in accordance with the applicable service agreement. Upon termination: - Work completed up to the termination date will be billed. - Outstanding payments remain payable. - Deliverables completed and paid for will be handed over as agreed.

15. Privacy

Your use of our website is also governed by our Privacy Policy, which explains how we collect, use, and protect your information.

16. Changes to These Terms

We reserve the right to modify these Terms & Conditions at any time. Updated versions will be published on this page with the revised effective date. Continued use of the website constitutes acceptance of the updated terms.

17. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India. Any disputes arising out of these terms shall be subject to the exclusive jurisdiction of the courts having jurisdiction over the Company's registered office.

18. Contact Information

IndiaTek Solutions Private Limited Email: info@indiatek.co Phone: +91 7482811911 Website: www.indiatek.co

Terms & Conditions